Loading...
Serving Springfield, VA and surrounding areas. (571) 788-4608
Effective date: January 1, 2026. Applies to springfieldconcreteco.com and all services provided by Custom Springfield Concrete.
By accessing or using the website at springfieldconcreteco.com, submitting a contact or estimate request, or engaging Custom Springfield Concrete to perform any services, you agree to be bound by these terms and conditions. If you do not agree to these terms, do not use this website or engage our services.
These terms apply to all visitors to the website, all persons who request estimates, and all customers who enter into a service agreement with Custom Springfield Concrete.
Custom Springfield Concrete is a concrete contractor providing residential and commercial concrete services in Springfield, VA and surrounding communities. Services include but are not limited to concrete driveway installation, patio construction, sidewalk building, foundation work, retaining walls, decorative concrete, and related services as described on our website.
All services are subject to a separate written service agreement. Nothing on this website or in an estimate constitutes a guarantee of availability, timeline, or final price until a signed contract is in place.
Estimates provided by Custom Springfield Concrete - whether verbal, written, or submitted through this website - are good-faith approximations based on information available at the time of assessment. Estimates are not fixed-price quotes unless stated in a signed written contract.
Final pricing may vary from the estimate if site conditions differ from what was observed during the initial visit, if the scope of work changes at the customer's request, or if material costs change significantly between estimate and project start. Any changes to scope or price will be communicated to the customer in writing before additional work proceeds.
Estimates are valid for 30 days from the date issued unless otherwise noted.
Project start dates are scheduled upon execution of a signed agreement and receipt of any required deposit. Scheduling is subject to weather conditions, permit approval timelines, and crew availability. We will communicate any delays promptly.
If you need to reschedule or cancel a project, please contact us as early as possible. Cancellations made after work has begun or after materials have been ordered and delivered may be subject to charges for work completed and materials purchased on your behalf. Specific cancellation terms will be stated in your service agreement.
Custom Springfield Concrete reserves the right to reschedule or suspend work due to unsafe weather conditions or circumstances outside our control. We will not charge for weather-related delays.
Payment terms are specified in your signed service agreement. In general, a deposit is required before work begins, with the remaining balance due upon project completion. Accepted payment methods will be listed on your contract.
Balances not paid within the timeframe specified in the service agreement may be subject to a late fee. Custom Springfield Concrete reserves the right to suspend or cease work on projects with outstanding balances. In the event that collection action is necessary, the customer agrees to pay reasonable costs of collection, including attorney fees, to the extent permitted by law.
Where required by local ordinance or county regulation, Custom Springfield Concrete will apply for necessary permits on the customer's behalf as part of the project scope. Permit fees are the responsibility of the customer and will be included in or added to the project estimate. The customer is responsible for obtaining any HOA approvals prior to work beginning. Custom Springfield Concrete is not responsible for delays caused by third-party permit review timelines or HOA review processes.
Custom Springfield Concrete warrants that all work will be performed in a workmanlike manner consistent with industry standards. Specific warranty terms - including duration and coverage - will be stated in the written service agreement for each project.
Warranty coverage does not apply to damage caused by misuse, failure to follow care instructions provided at project completion, acts of nature, settlement or movement caused by conditions not disclosed or observable at the time of installation, or modifications made by parties other than Custom Springfield Concrete.
THE WEBSITE AND ITS CONTENTS ARE PROVIDED "AS IS" WITHOUT WARRANTY OF ANY KIND. CUSTOM SPRINGFIELD CONCRETE MAKES NO WARRANTY THAT THE WEBSITE WILL BE UNINTERRUPTED, ERROR-FREE, OR FREE OF VIRUSES OR OTHER HARMFUL COMPONENTS. THE INFORMATION ON THIS WEBSITE IS FOR GENERAL INFORMATIONAL PURPOSES AND DOES NOT CONSTITUTE PROFESSIONAL ADVICE. RELIANCE ON ANY INFORMATION ON THIS WEBSITE IS AT YOUR OWN RISK.
To the fullest extent permitted by applicable law, Custom Springfield Concrete and its owners, employees, and contractors shall not be liable for any indirect, incidental, special, or consequential damages arising from the use of this website or from the performance of services. This includes, without limitation, lost profits, loss of data, or damage to property not directly caused by our work.
In all cases, our total liability to you for any claim arising from services performed shall not exceed the amount you paid us for the specific project giving rise to the claim.
If a dispute arises between you and Custom Springfield Concrete, we ask that you contact us directly first so that we can try to resolve it informally. Reach us at estimates@springfieldconcreteco.com or (571) 788-4608.
If the dispute cannot be resolved informally, the parties agree to submit the matter to binding arbitration in accordance with the rules of the American Arbitration Association, conducted in Springfield, Virginia. The arbitrator's decision will be final and binding, and judgment may be entered in any court of competent jurisdiction.
You agree to resolve any claims individually and waive the right to participate in any class action or representative proceeding.
These terms and any disputes arising from them are governed by the laws of the Commonwealth of Virginia, without regard to its conflict of law principles. Any legal action not subject to arbitration shall be brought exclusively in the courts of Virginia.
All content on this website - including text, images, logos, and layout - is the property of Custom Springfield Concrete or its licensors. You may not copy, reproduce, distribute, or create derivative works from any content on this site without our prior written permission.
Custom Springfield Concrete reserves the right to update these terms at any time. Changes will be posted on this page with an updated effective date. Your continued use of the website or engagement of our services after any changes constitutes your acceptance of the revised terms. We encourage you to review this page from time to time.
Questions about these terms? Reach out to us directly.
Custom Springfield Concrete
7052 Floyd Ave, Springfield, VA 22150